Welcome to National Solar Installation. By accessing and using our website or services, you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully before using our website.
By using our website, you acknowledge that you have read, understood, and agreed to these Terms and Conditions. If you do not agree, please discontinue using our website and services.
National Solar Installation provides solar energy solutions, including installation, maintenance, and related services. All services are subject to availability, project scope, and agreement between the company and the client.
When using our website, you agree to:
Provide accurate and truthful information when filling out forms or communicating with us
Not use the website for any unlawful purpose or to violate the rights of others
Not attempt to interfere with the website’s functionality or security
All content on this website, including text, graphics, logos, images, and design, is the property of National Solar Installation unless otherwise stated. Unauthorized use, reproduction, or distribution of this material is prohibited.
Any quotes or estimates provided by National Solar Installation are based on the information available at the time and may be subject to change after a full site assessment. Final pricing and project details will be outlined in a written agreement between both parties.
Payment terms will be clearly stated in the service agreement. Late or incomplete payments may result in delays, suspension of services, or additional charges.
National Solar Installation is not responsible for:
Any indirect, incidental, or consequential damages arising from the use of our services or website
Delays or disruptions caused by factors beyond our control, including weather, supply chain issues, or third-party actions
We strive to provide reliable and high-quality solar solutions. Specific warranties related to products or services will be outlined in the service agreement. Apart from these, we make no other warranties, expressed or implied.
We reserve the right to terminate or restrict access to our website or services if you violate these Terms and Conditions or engage in any harmful activity against the company.
Our website may contain links to third-party websites. National Solar Installation is not responsible for the content, accuracy, or practices of these external sites.
National Solar Installation may update or modify these Terms and Conditions at any time. Changes will take effect immediately upon being posted on this page. Continued use of our website or services signifies your acceptance of the updated terms.
These Terms and Conditions are governed by and interpreted in accordance with the laws of Thailand. Any disputes shall be subject to the jurisdiction of the courts located in Huahin, Thailand.
If you have any questions about these Terms and Conditions, please contact us at:
National Solar Installation
Email: sales@nationalsolarinstallation.com
Phone: 091 727 4710
Address: 41/225 Soi Moobaan Khaonoi Huahin Prachuap khirikhan
